How We Do Business.
Terms & Conditions
Effective Date: April 12, 2026
1. Acceptance of Terms
By accessing KurtCFS.com or engaging services with Kurt Commercial Facility Services, LLC (“Company”), you agree to be legally bound by these Terms.
2. Scope of Services
Services include energy solutions, renovations, preventative maintenance, and consulting for residential and commercial properties. All services require written approval via estimate, proposal, or contract.
3. No Guarantee of Outcomes
The Company does not guarantee:
Energy savings
Performance outcomes
Timelines free from delays
All outcomes are influenced by external factors beyond Company control.
4. Client Responsibilities
Clients must:
Provide accurate and complete information
Maintain safe and accessible work environments
Ensure compliance with applicable laws
Provide timely approvals and decisions
5. Payment & Financial Terms
Deposits may be required
Payments must be made per contract terms
Late payments may result in fees, liens, or service suspension
6. Limitation of Liability
To the fullest extent permitted by law, Company liability is limited to the amount paid for services. The Company shall not be liable for:
Indirect or consequential damages
Lost profits or business interruption
7. Indemnification
You agree to indemnify, defend, and hold harmless the Company from any claims, damages, liabilities, costs, or expenses arising from:
Your misuse of services
Inaccurate information provided
Failure to comply with laws or safety requirements
8. Arbitration Agreement
Any dispute shall first be resolved through binding arbitration, administered by an arbitration provider selected solely by the Company. Arbitration shall occur in Missouri.
You waive the right to:
Jury trial
Class action participation
9. Termination
We reserve the right to terminate services or access for violations of these Terms.
10. Governing Law
Missouri law governs these Terms.
11. Modifications
Terms may be updated at any time.
12. Contact
service@kurtcfs.com
844-434-9694
Privacy Policy
Effective Date: April 12, 2026
1. Data Collection
We collect personal, technical, and usage data through forms, communications, and automated technologies.
2. Expanded Use of Data
We may use data for:
Service delivery
Risk management
Fraud prevention
Legal enforcement
3. Data Sharing
Data may be shared with:
Contractors and vendors
Legal authorities
Business successors in the event of sale or restructuring
4. Data Security Disclaimer
While we implement safeguards, we cannot guarantee absolute security. Use of the site is at your own risk.
5. Indemnification
You agree to indemnify and hold harmless the Company from claims arising out of:
Your submission of false or unlawful data
Unauthorized use of the website
Violations of privacy laws caused by your actions
6. Arbitration Clause
All privacy-related disputes shall be resolved via binding arbitration selected by the Company in Missouri.
7. Limitation of Liability
We are not liable for:
Data breaches beyond reasonable control
Third-party misuse of data
8. Retention & Deletion
We retain data as necessary for operational and legal purposes.
9. Contact
Cookie Policy
1. Technology Use
We use cookies, pixels, and tracking technologies.
2. Expanded Purpose
Cookies support:
Site functionality
Analytics
Marketing optimization
Fraud detection
3. Third-Party Tools
Third parties may collect data via cookies.
4. User Responsibility
You are responsible for managing cookie settings.
5. Indemnification
You agree to indemnify the Company from claims related to:
Your misuse of tracking technologies
Violations of third-party platform terms
6. Arbitration
All disputes regarding cookies or tracking technologies shall be resolved through Company-selected arbitration.
7. Limitation of Liability
We are not liable for third-party tracking or data collection practices.
8. Contact
Legal Disclaimer
1. Informational Use Only
Content is not guaranteed to be accurate or complete.
2. No Professional Liability
No engineer-client or contractor-client relationship is formed solely by website use.
3. Indemnification
You agree to indemnify the Company from claims resulting from:
Reliance on website content
Improper implementation of recommendations
4. Arbitration Requirement
All disputes must go through binding arbitration selected by the Company.
5. Limitation of Liability
We are not liable for damages arising from reliance on site content.
6. Risk Acknowledgment
Users assume full responsibility for use of information.
7. Contact
Return & Refund Policy
1. Service-Based Nature
All services are customized and non-returnable.
2. Deposits & Payments
Deposits may be non-refundable once scheduling or procurement begins.
3. Indemnification
You agree to indemnify the Company from disputes arising from:
Project cancellations
Scope misunderstandings
Payment disputes
4. Arbitration Requirement
All refund disputes shall be resolved via Company-selected arbitration.
5. Limitation of Liability
Refunds are limited to amounts paid and do not include consequential damages.
6. Chargeback Protection
Unauthorized chargebacks will be pursued legally.
7. Contact
Copyright Notice
1. Ownership
All content is owned by Kurt Commercial Facility Services, LLC.
2. Indemnification
You agree to indemnify the Company from claims resulting from:
Unauthorized use of content
Intellectual property violations
3. Arbitration
All disputes regarding intellectual property shall be resolved through Company-selected arbitration.
4. Enforcement
We reserve the right to pursue legal action.
5. Contact
EULA
1. License Grant
We grant a limited license to use the website.
2. Restrictions
You may not misuse, copy, or exploit content.
3. Indemnification
You agree to indemnify the Company from claims arising from misuse of the website.
4. Arbitration
All disputes shall be resolved via Company-selected arbitration.
5. Limitation of Liability
We are not liable for damages from site usage.
6. Termination
Access may be revoked at any time.
7. Contact
Affiliate Disclosure
1. Compensation
We may receive compensation for referrals.
2. Indemnification
You agree to indemnify the Company from claims related to:
Third-party products or services
Misuse of recommendations
3. Arbitration
All disputes shall be resolved via Company-selected arbitration.
4. No Guarantees
We do not guarantee outcomes from third-party products.
5. Contact
Master Service Agreement
Effective Date: April 12, 2026
This Master Service Agreement (“Agreement”) is entered into between Kurt Commercial Facility Services, LLC (“Company”) and the Client.
1. Scope of Services
Company provides energy solutions, renovations, preventative maintenance, and consulting services. Specific work will be defined in written proposals, estimates, or work orders.
2. Independent Contractor
Company is an independent contractor and not an employee, agent, or partner of Client.
3. Estimates & Change Orders
All pricing is based on initial project scope
Changes require written approval
Additional work will be billed accordingly
4. Site Conditions & Unknowns
Client acknowledges:
Hidden conditions (mold, structural issues, code violations, etc.) may exist
Discovery of such conditions may result in additional costs and timeline changes
5. Permits & Compliance
Unless otherwise agreed:
Client is responsible for permits
Company may assist but does not guarantee approval
6. Scheduling & Delays
We are not responsible for delays caused by:
Weather
Material shortages
Third parties
Client delays
7. Payment Terms
Deposits required as stated
Progress payments may apply
Late payments may result in liens, interest, or stoppage of work
8. Warranty Disclaimer
Unless explicitly stated:
No warranties beyond manufacturer warranties
Preventative maintenance reduces risk but does not eliminate failure
9. Limitation of Liability
Liability is limited to the amount paid. Company is not liable for:
Consequential damages
Business interruption
Lost revenue
10. Insurance
Company maintains commercially reasonable insurance. Proof available upon request.
11. Indemnification
Client agrees to indemnify, defend, and hold harmless Company from claims arising out of:
Site conditions
Client negligence
Failure to disclose hazards
Third-party actions
12. Safety
Client must provide a safe working environment. Unsafe conditions may result in work stoppage.
13. Arbitration (MANDATORY)
All disputes shall be resolved through binding arbitration selected solely by the Company, held in Missouri.
Client waives:
Jury trial
Class actions
14. Termination
Either party may terminate in writing. Client remains responsible for work completed and costs incurred.
15. Entire Agreement
This Agreement supersedes all prior discussions.
16. Contact
service@kurtcfs.com
844-434-9694
Proposal/Estimate Terms
1. Acceptance
Approval of this estimate constitutes agreement to all terms herein and the Company’s Master Service Agreement.
2. Pricing Validity
Pricing is valid for [30] days (or otherwise noted) and subject to change due to:
Material cost increases
Labor fluctuations
3. Scope Limitations
This proposal includes only listed work. It excludes:
Hidden damages
Code upgrades unless specified
Hazardous material remediation
4. Access to Site
Client must provide:
Clear access
Utilities
Safe working conditions
5. Payment Terms
Deposit required to schedule
Progress payments may apply
Final payment due upon completion
6. Delays
We are not responsible for delays beyond our control.
7. Indemnification
Client agrees to indemnify Company from claims related to:
Property conditions
Third-party interference
Inaccurate project information
8. Arbitration
All disputes shall be resolved via Company-selected arbitration in Missouri.
9. Cancellation
Cancellation may result in fees for work completed and materials ordered.
10. Contact
ADA/Accessibility Statement
Kurt Commercial Facility Services, LLC is committed to improving accessibility in both digital and physical environments.
1. Website Accessibility
We strive to align with Web Content Accessibility Guidelines (WCAG), but do not guarantee full compliance at all times.
2. Building Accessibility Services
Our services may include accessibility improvements; however:
3. No Compliance Guarantee
We do not guarantee:
ADA compliance certification
Legal compliance outcomes
Final compliance depends on:
Local codes
Building conditions
Regulatory interpretation
4. Client Responsibility
Client is responsible for:
Final compliance verification
Legal consultation if required
5. Indemnification
Client agrees to indemnify Company from claims related to:
Accessibility compliance disputes
Regulatory enforcement actions
6. Arbitration
All disputes shall be resolved via Company-selected arbitration.
7. Contact
Construction/Facility Liability Addendum
1. Inherent Risk Acknowledgment
Client acknowledges construction and maintenance work involves risks including:
Property damage
Equipment failure
Unexpected conditions
2. Existing Conditions Disclaimer
We are not responsible for:
Pre-existing structural issues
Undisclosed hazards
Prior improper work
3. Utility & Infrastructure Risks
Client must identify:
Utilities
Structural limitations
We are not liable for damage due to inaccurate information.
4. Material & Equipment Variability
Performance of materials and systems may vary. No guarantees beyond manufacturer warranties.
5. Environmental Conditions
We are not liable for:
Mold
Water intrusion
Environmental hazards discovered during work
6. Indemnification
Client agrees to indemnify Company from claims related to:
Site hazards
Third-party injuries
Environmental conditions
7. Arbitration
All disputes shall be resolved via Company-selected arbitration.
8. Limitation of Liability
Liability capped at amount paid.
9. Contact
Insurance & Risk Allocation Clause
1. Company Insurance
We maintain commercially reasonable:
General liability insurance
Workers’ compensation coverage*
2. Client Insurance Responsibility
Client is responsible for maintaining:
Property insurance
Builder’s risk (if applicable)
3. Risk Transfer
Client assumes risk for:
Property damage beyond our control
Acts of third parties
4. Waiver of Subrogation
To the extent permitted by law, Client waives rights of subrogation against Company.
5. Indemnification
Client agrees to indemnify Company against claims not caused by Company negligence.
6. Arbitration
All disputes resolved via Company-selected arbitration.
*Waiver provided in some cases.
7. Contact
Warranty & Performance Disclaimer
1. Limited Warranty
Any warranties must be explicitly stated in writing.
2. No Performance Guarantee
We do not guarantee:
Energy savings
Equipment lifespan
Maintenance outcomes
3. Third-Party Products
Subject to manufacturer warranties only.
4. Maintenance Limitation
Preventative maintenance reduces risk but does not eliminate failure.
5. Indemnification
Client agrees to indemnify Company from claims related to:
System performance
Equipment failure
6. Arbitration
All disputes resolved via Company-selected arbitration.